Terms & Conditions

Last updated: 8 October 2026

1. About these terms

These terms apply to your use of our website and to enquiries, estimates and construction services provided by End to End Constructions Pvt Ltd (“End to End Constructions”, “we”, “us”), 2nd Floor, BB Road, Opp. Shani Mahathma Temple, Near Maruti TVS Showroom, Chikkaballapura KA 562101. By using our website or engaging us, you agree to these terms. Once you sign a construction agreement with us, that agreement and its attachments apply together with these terms. If they conflict, the signed agreement prevails.

2. Our services

We provide residential, commercial and industrial construction, including 2D and 3D drawings, architecture and elevation design, super structure work, and interior design solutions. The exact services for your project are those described in your written estimate or agreement.

3. Packages, estimates and pricing

• Package rates (such as Standard, Premium and Luxury) are shown per square foot and apply to the built-up area described in your estimate. Rates on our website are for guidance and may change before an agreement is signed.
• Each package lists materials, brands and budgets. Where an item is shown as “upto” an amount, that amount is the budget included in the package. If you choose an item that costs more, you pay the difference.
• Items stated as not part of the package, such as chajjas and window grills in certain packages, are charged extra at the rates stated in the package details.
• Prices are as stated in your written estimate or agreement, which also states whether GST is included or extra.
• Estimates are valid for 5 days from the date issued.

4. Payments

Payments are made as set out in the agreement, We may pause work if payments are overdue, and the delay caused by the pause is not counted against us. Please pay only by bank transfer or other traceable methods to the account named in your agreement, and obtain a receipt for every payment.

5. Changes to the scope of work

Any change to the design, specifications or quantities after the agreement is signed (a “change”) must be requested in writing, including by email or WhatsApp message. We will tell you the effect of the change on cost and time before we carry it out. We will start work on a change only after you approve the revised cost and time.

6. Approvals, documents and site access

• You confirm that you own the plot or have the right to build on it, and you will give us the land documents we reasonably ask for, such as the title deed, khata and tax receipts.
• We guide you through the approvals needed for your project. Unless the agreement says otherwise, the approval fees and any charges payable to authorities are paid by you, and approvals are granted by the authorities, not by us.
• You will give us clear access to the site, together with water and electricity where the agreement requires, and you will tell us about any boundary disputes or restrictions on the plot.

7. Materials and brands

We use the materials and brands listed in your package or agreement. If a listed item is unavailable or its supply is delayed, we may substitute an item of equal or better quality and specification, and we will tell you about it. Colour, texture and finish of natural and manufactured materials may vary slightly from samples and photographs.

8. Timelines and delays

Any completion date we give is an estimate based on the information available at the time. The schedule may be extended by events outside our reasonable control, including delays in approvals, late payments, late decisions or changes by you, restricted site access, unusually heavy rain or other severe weather, strikes, shortages of materials or labour, government orders and force majeure events. We will inform you of any expected delay and its cause as early as we reasonably can.

9. Quality, defects and warranty

We carry out our work with reasonable skill and care and to the specifications in your agreement. We inspect the work at each stage, and you are welcome to visit the site at reasonable times. We will repair defects in our workmanship that you report to us in writing within warranty period. Warranties on fittings, fixtures and equipment are provided by their manufacturers and suppliers. The warranty does not cover damage caused by misuse, lack of maintenance, alterations by others, natural wear, or events such as floods and earthquakes.

10. Your responsibilities

• Give us accurate information and make decisions on designs, selections and approvals within a reasonable time.
• Do not give instructions to our workers directly or bring in other contractors for the same work without telling us, as this may affect quality, safety and the schedule.
• Take possession of the completed work when it is ready and offered, after clearing all dues under the agreement.

11. Cancellation and termination

If you cancel before work starts, we will refund the amounts you have paid after deducting the costs we have already incurred, including design, drawing and approval work, and cancellation charge, if any. If you cancel after work starts, you will pay for the work completed, materials purchased or ordered for your project, and any reasonable costs of closing the site. Either of us may end the agreement if the other breaches it seriously and does not correct the breach within 7 days of written notice.

12. Designs and drawings

The drawings, designs and plans we prepare remain our intellectual property until you have paid for them. After payment you may use them to build and maintain the project they were prepared for. You may not copy them for other projects or share them with others for use elsewhere without our written permission. We may photograph the completed project and show it in our portfolio and marketing, without sharing your personal details, unless you ask us not to.

13. Limitation of liability

To the extent permitted by law, we are not responsible for indirect or consequential losses, such as loss of rent, income or business, arising out of delays or defects. Our total liability for any claim relating to a project is limited to the amount you have paid us for that project. Nothing in these terms limits liability that cannot be limited by law.

14. Website, enquiries and communication

• Information on our website, including package details, images and sample screens, is for general guidance only. It does not form an offer, and the signed agreement governs the services.
• When you send an enquiry through our website form, WhatsApp or phone, you allow us to contact you about your project by phone, WhatsApp, SMS and email. We use your details only to respond to your enquiry and to provide our services, and we do not sell them to others. See our Privacy Policy for more details.
• Do not misuse our website, attempt to access it without authorisation, or copy its content without our written permission.

15. Disputes and governing law

We will try to resolve any dispute through discussion first. If it is not resolved within 7 days, [either refer it to arbitration in Bengaluru under the Arbitration and Conciliation Act, 1996, or state another method]. These terms are governed by the laws of India, and the courts at Bengaluru jurisdiction.

16. Changes to these terms

We may update these terms from time to time. The updated version will be posted on this page with a new “last updated” date. Changes do not affect agreements already signed unless both of us agree.

17. Contact us

For any questions about these terms, contact End to End Constructions by email at endtoendconstructionspvt@gmail.com or on WhatsApp at +91 95460 59546.